industriously definition: 1. with a lot of hard work or effort: 2. with a lot of hard work or effort: . Assessing whether the definition of failing to proceed regularly and diligently has been satisfied is very much a question of judgement and must be assessed against the backdrop of what evidence is available to prove a lack of diligence. California's TAX Portal. For the Contractor, ensuring you have the necessary records to support any claims going forward, and taking steps to minimise any financial losses by, for example, terminating your subcontractors as soon as possible,14 is crucial. 0 && stateHdr.searchDesk ? This interval was diligently devoted to the pursuit of classical and historical studies, to preparing himself for ordination, and to searching investigations, under the stimulus of continual discussion with a band of talented and congenial associates, of the profoundest questions in theology, ecclesiastical polity and social philosophy. The brothers worked diligently to build a tree house. When you consider that working out diligently could help you loose six pounds in six weeks, it can be worth the wait. Any opinions in the examples do not represent the opinion of the Cambridge Dictionary editors or of Cambridge University Press or its licensors. California Occupational Guide. The male shaman had an inner woman or wife whom he listened to closely and who guided him. working 1 of 2 adjective 1 as in operating being in effective operation the only working coal mine in the area Synonyms & Similar Words Relevance operating operational running going operative functioning on active living live in force functional on line operable in commission producing alive performing serving viable in gear into commission For the Contractor, if such evidence has not been taken, then half your job has already been done for you. The records preserved in each city were examined, topographical information was diligently collected, and the Jesuit fathers checked their triangulation by meridian altitudes of the sun and pole star and by a system of remeasurements. Contains Parliamentary information licensed under the. The JCT form provides for a two-stage process. Thereafter he had no settled charge, but, until his death at Hartford on the 17th of February 1876, he occasionally preached and was diligently employed as an author. What are similar words for dilly dallier. He had diligently studied the works of Jacob Boehme, and there were found amongst his manuscripts copious abstracts from them in his own handwriting. Because you know theyre not really scary creatures theyre just kids dressed up in costumes so they can get candy. Although the employer may be able to monitor progress more objectively, it is much less flexible and any changes to the milestone dates or to the contractors programming may well constitute a variation, with the resulting time and cost consequences for the employer. Why dont you run away, screaming in terror? Diventa un Sostenitore di WordReference per vedere il sito senza pubblicit. When you consider that working out diligently could help you loose six pounds in six weeks, it can be worth the wait. Download Working Solutions and enjoy it on your iPhone, iPad, and iPod touch. Does the Limitation Act 1980 apply to adjudication? A diligent person is he who shows persistent and hardworking effort in doing something. As the judge in that case made clear, the success or otherwise of this argument will depend upon the terms of the contract in question and what is required to achieve the completion date. WordReference . Privacy Policy. working 2 of 2 adjective 1 : engaged in work especially for wages or a salary a working journalist a working mother 2 : adequate to permit work to be done a working majority 3 : assumed or Get this wrong and the Contractors employment will not have been terminated but the Employer may be in repudiatory breach of contract. Most employers want to rely on their contractors experience and expertise to resource, plan and programme the works and achieve completion by the specified date. On the other hand, it is known that it was being diligently, copied by Assur-bani-pal's scribes (7th century B.C. For our active agents: Schedule your work hours for programs, check your invoices, stay informed on all new contract opportunities and receive important alerts via push notifications on the new Working Solutions mobile app. All too often a vital few weeks of evidence gathering can be missed. Using the word opinion. (Now hand over the candy.). working ( wk) n 1. the operation or mode of operation of something 2. the act or process of moulding something pliable 3. Calorie counting works to lose or maintain weight when done diligently. Recent court guidance. We have listed all the similar and related words for diligently alphabetically. (Mining & Quarrying) ( often plural) a part of a mine or quarry that is being or has been worked 5. Conditional Sentences: Examples of the Different Types, What Is a Gerund? With this in mind, we look at the kind of evidence that an Employer should collect if the worst happens and the Contractor is failing to proceed regularly and diligently (often in practice accompanied by signs that their financial status is less then ideal). With on-demand service, better engage, empathize, and delight your customers, wherever and whenever they Learn more. These vegetarians will learn, and fast, that they need to diligently read food labels. He is enamored by small and cute things, and thus favors Popura over the other employees due to her cute appearance. "If" one thing happens, "then" another thing will happen. 3. Cold working or cold forming, the shaping of metal below its recrystallization temperature. Evidence of delay when compared to a contract programme is always going to be helpful but, as set out below, is not on its own sufficient. A contractor may be able to re-programme, rather than accelerate, the works to mitigate its own delay, which it is entitled to do under most forms of construction contract. "diligently" Greek . Equally if the resources are as planned but there is still delay, then this may be used by a contractor to evidence they are proceeding regularly and diligently. However, if a contractor fails to accelerate in these circumstances could that be further evidence of a lack of due diligence? According to the title-page the New Testament was " translated faithfvlly into English ovt of the authentical Latin, according to the best corrected copies of the same, diligently conferred vvith the Greeke and other editions in diuers languages.. At Cambridge he applied himself diligently to the several sciences as then taught, and came to the conclusion that the methods employed and the results attained were alike erroneous. Working supervisors also handle timekeeping records, employee training, performance reports, and employee concerns. (, Poor labour management and inadequate supervision does not necessarily establish (on its own) that a contractor is not proceeding regularly and diligently (, The fact that a contractual obligation (that is, achieving the completion date) has become impossible does not render the separate obligation of due diligence irrelevant or less onerous. On a typical day, they work in semi-private or private offices, communicate with team members and other people in management, attend meetings, and conduct coaching sessions as needed. 2023 LoveToKnow Media. Encouraged by their success, he devoted himself diligently to this kind of composition, but refrained for a long time from either publicly reciting or publishing his verses. That I consider is the best evidence in this case of a failure by Redhall to proceed with the works regularly and diligently, as that phrase was defined in West Faulkner.. However, employers may now seek to rely on the Sabic case as giving them the right to insist that the contractor accelerate the works, at its own cost, as part of its obligation to proceed with due diligence to achieve the specified completion date. Google Translate diligently. Their investigation has since been diligently prosecuted. Click on the arrows to change the translation direction. New amalgams and methods of colouring have been discovered, and fresh forms have been diligently studied. working meaning: 1. relating to work: 2. having work: 3. operating: . In contrast, Mr Justice Ramsey did not consider that a lack of supervision (without more evidence in support) would be enough to found a separate ground for establishing a failure to proceed regularly and diligently.7 Similarly, allegations of poor material controls, rework of defective fabrication and inadequate management of scaffolding resources were deemed not to add much further to the evidence already put forward. Even though the aforementioned steps to avoid constipation may be followed diligently by parents, there are some kids who simply seem to have a propensity toward having problems with bowel movements. 'diligently' : : beaver away - buckle down - conscientiously - dutifully - hard worker - religiously - rigorously - studiously - take pains to do / diligently : "diligently" Greek . Live-line working, the maintenance of electrical equipment while it is energised. What is clear then is that delay on its own is not a failure to proceed regularly and diligently. If you're serious about fading your stretch marks, hit the drugstore and stock up on either cocoa butter or aloe Vera gel and apply them diligently, concentrating on the areas that are the most burdensome and embarrassing. Importantly then, a failure to proceed regularly and diligently with the works has to be judged against the contractual requirements of the contract as a whole and not just in terms of timing. Your email address will not be published. Conflicting, positive or strongly held? Conditional sentences describe a conditional situation, or a result that depends on an event occurring first. Concurrent delay: the latest guidance from the courts, Delay does not of itself provide conclusive proof of a lack of due diligence, but it may suggest and evidence a lack of due diligence (, Failing to achieve the programmed productivity because of inadequate resourcing will usually evidence a failure to proceed regularly and diligently (, Where an employer is actively trying to manage and mitigate any delay caused by its contractor and requests the contractor to re-deploy resources to higher priority areas, this may jeopardise any subsequent claim that the contractor has failed adequately to resource the works. Schools are being diligently built; but the wants of the natives are subordinated to the supposed necessities of Russification. Multiple working, having more than one locomotive under the control of one driver. However, proving a lack of due diligence is notoriously difficult. At the same time he diligently pursued the practice of his profession. from the works or the assignment of the benefit of any agreements for the supply of materials or goods for the execution of any other works.16 In doing so, bear in mind you may well end up with a pile of unpaid invoices if you do choose to take on any suppliers or subcontractors who were previously on the project. His contemporary, Cassiodorus (c. 480-c. 575), after spending thirty years in the service of the Ostrogothic dynasty at Ravenna, passed the last thirty-three years of his long life on the shores of the Bay of Squillace, where he founded two monasteries and diligently trained their inmates to become careful copyists. Personal Care Aides, Occupation with the Most Openings. Privacy Policy. 3. Rather, they worked diligently studying their craft and practicing basic techniques and composition. Working diligently crossword clue. Virgo's partner can expect that this sign will work diligently to correctwhatever ails their relationship, not just out of love, but out of principle. Second, learn your company's sexual harassment prevention policy and follow it diligently. The ample revenues which his predecessors had consumed in pomp and luxury he diligently applied to the establishment of hospitals; and the multitudes who were supported by his charity preferred the eloquent discourses of their benefactor to the amusements of the theatre or of the circus. Sign up to make the most of YourDictionary. 1. One can check verbs forms in different tenses. The meaning of HARDWORKING is constantly, regularly, or habitually engaged in earnest and energetic work : industrious, diligent. The priests diligently practise all the precepts of their rituale.g. Their investigation has since been diligently prosecuted. # phone # working # busy # fred willard # tim and eric awesome show great job. A contractor must be allowed to do this as he sees fit, but this makes proving a lack of due diligence difficult. Type Greek characters with a virtual keyboard. Unfortunately, the requested page is unavailable, inaccessible, unreachable at this moment. The crossword clue possible answer is available in 4 letters. The next step is to serve the requisite notices in accordance with the terms of the contract. Large sums have been expended on the destruction of locusts; they are now practically harmless, but live locusts are diligently collected every year, a reward being paid by the government for their destruction. We have the perfect digital job opportunities for those looking to start their telecommuting career. There is evidence that he was an extensively read, if not a minutely accurate classical scholar; and it is interesting to know that Demosthenes was his favourite author, and that he diligently cultivated the faculty of expression by the practice of translation and re-translation. For an Employer wishing to terminate for a failure to proceed regularly and diligently, gathering the evidence to support the termination in advance is absolutely key to a successful result, should the termination be challenged. The first notice (the default notice otherwise known as a hurry-up notice10) sets out the failure to proceed regularly and diligently, whilst the second notice (only to be issued if the same behaviour continues for 14 days from the default notice and within 21 days of that) terminates the Contractors employment under the contract. Many building contracts require the contractor to carry out and complete the works by the completion date and also to proceed with the works regularly and diligently. There is a paradox here. However, when the phrase has come before the Courts, it has become evident that trying to define what it actually means in practice is by no means an easy task. How to use hardworking in a sentence. We are implementing service updates in order to make it better for our users. Trying to find another word for diligently in English? The Canadian home for local and national job seekers They do not represent the opinions of YourDictionary.com. Greek models were diligently studied by Virgil and Horace. Waiting until after the first warning notice has been issued under clause 8.4.1 to start assembling the evidence to support it is far from ideal. Use a sunscreen diligently to keep spots from re-darkening during treatment. Entering the university of Erlangen in 1843, he soon began to devote his attention to the history of the German language and literature, and in 1848 went to Munich, where he remained five years, and diligently availed himself of the use of the government library for the purpose of prosecuting his historical studies. Working is an American sitcom television series that aired on NBC for two seasons from October 8, 1997 to January 25, 1999. and For the Contractor the next step will, in all likelihood, be to assert that their employment under contract has not been terminated properly because they had not failed to proceed with the works regularly and diligently and/or the notices were not properly issued. Get it right and clause 8.7 provides a useful toolbox for the Employer for getting on with the works and the ability to postpone paying any monies which may be due to the Contractor until after the completion of the works and the making good of defects.2. Learn more. A working person is employed: working mothers working adjective [not gradable] (PERFORMING AS INTENDED) performing as intended and doing what it is supposed to do: The mechanic finally Explore the various types of conditional sentences and review a few examples of each. Test your vocabulary with our fun image quizzes, Clear explanations of natural written and spoken English. Some facets of communication and discussion are innate, but a person who isn't gifted with social graces or an outgoing personality can still become successful at public relations by studying diligently. What are the related words for dill pickle? Conversely, it also provides guidance for Contractors seeking to establish that the Employer has repudiated their contract, or will do so, if it seeks to terminate their employment on that ground. Welcome to Working.com! These examples are from corpora and from sources on the web. His object was to make all the anatomical and physiological acquisitions of his age, even microscopical anatomy, which he diligently studied, available for use in the practice of medicine. He kept on diligently collecting materials, and as he did so was constrained to modify some of the statements he had published. Trying to find another word for diligently in English? Remixers work diligently on their own projects, using songs from as far back as the Commodore 64 through the Super Nintendo Entertainment System and today's PlayStation 2, Xbox, Game Cube and Game Boy hits. Our thesaurus contains synonyms of diligently in 38 different contexts. Thats what gerunds do: They pretend to be a different part of speech to make a sentence work. Have the 14 days expired since the default notice was properly served? The contractor is obliged to progress the works with due diligence. Hot working, the shaping of metal above its recrystallization temperature. No matter how diligently you've planned, there will always be surprises as you begin the retirement phase of your life. In that case Mr Justice Ramsey viewed a lack of productivity as being the best evidence of a failure to proceed regularly and diligently.5 However, he also noted that the failure to provide a proper programme (and one in accordance with their contractual obligations) undoubtedly resulted, in that case, in an inability to proceed continuously, industriously and efficiently with appropriate physical resources so as to progress the works towards completion.6. So what evidence should be obtained? (Pathology) a convulsive or jerking motion, as from excitement 4. I love Working Solutions. In 1834 his political friend and colleague John Todd Stuart (1807-1885), a lawyer in full practice, had urged him to fit himself for the bar, and had lent him text-books; and Lincoln, working diligently, was admitted to the bar in September 1836. At the close of 1591 he was acting as the earl's confidential adviser, and exerted himself, together with his brother Anthony, diligently in the earl's service. How many other words for dillettantes are listed on this site? The simple rule on notices of termination is that you cannot be too careful. Finally, the wording of the final notice should include reference to common law rights to terminate (reserved under clause 8.3.1 of the JCT Standard Building Contract) and an appropriate reservation of rights.13. Stimulated by the high price paid by the British Museum, the quarry owners diligently searched, and in 1872 another, much finer, preserved specimen was found. Meanwhile, the French in Metz had been diligently at work. If correct, then the Employer is in repudiatory breach of contract and the Contractor is entitled to claim damages. Done with meticulousness and extreme attention to detail Adverb Actively, or with great endeavor or resolve assiduously actively arduously determinedly hard industriously intently laboriously purposefully resolutely amain busily conscientiously doggedly intensely intensively obstinately perseveringly sedulously slavishly steadfastly strenuously Diligently and industriously are synonyms Script Error - 500 Please try again in a few minutes. Yes! , by planning carefully and working diligently [repeating a preposition], looked out for the penitence as diligently, Study diligently and make progress everyday. website for synonyms, antonyms, verb conjugations and translations. It then suggests some practical advice for Employers deciding whether they can terminate the Contractors employment (and the risks of doing so) on that ground. It is the luxurious and dissipated who set the fashions which the herd so diligently follow. The female shaman had the inner husband. Limiting time in the sun, avoiding mid-day rays, and using sunscreen diligently will help hold back the years. He was one of the first Muscovites who diligently collected foreign books, and we hear of as many as sixty-nine Latin works being sent to him at one time from abroad. However it seems to me that, save in the most obvious of cases, a contractor will have a number of responses to this argument, not least that it is not responsible for all or part of the delay and is not required to accelerate the works to mitigate the effects of employer delay unless it is paid to do so. Tm hiu thm. 2023 LoveToKnow Media. The training is extensive; everyone is friendly, eager to assist with any questions or problems you may be having learning the line you are working for; and most importantly, the pay checks are deposited like clock work. The fraud will be investigated just as diligently on a family member as it would be if the fraudulent use was by someone you don't know. The brothers worked diligently to build a tree house. Vedi la traduzione automatica di Google Translate di "diligently". Because people are urged to wear sunscreen diligently and some people don't get outside much, it's easier now to have a vitamin D deficiency than in the past. Unless the contract provides otherwise, a contractor is entitled to programme and plan the works as it sees fit to achieve completion by the completion date. In Vivergo Fuels Limited v Redhill Engineering Solutions Limited9 the TCC stated that a failure to provide the level of resource shown in a programme would itself be evidence of a failure to proceed regularly and diligently. working / ( wk) / noun the operation or mode of operation of something the act or process of moulding something pliable a convulsive or jerking motion, as from excitement (often plural) a 'diligently' si trova anche in questi elementi: Nella descrizione in inglese: beaver away - buckle down - conscientiously - dutifully - hard worker - religiously - rigorously - studiously - take pains to do Italiano: diligentemente - di buzzo buono Forum discussions with the word (s) The Minnesota government is working diligently to stop the trend of foreclosures since the situation is not only bad for homeowners, but for the entire community as well. Is it in breach of this obligation? If the final notice is found to have been issued without the requisite grounds being satisfied, the contract will have been repudiated leaving the Employer open to claims for loss of profit at precisely the same time that they are seeking to get the job finished by others. Sign up to make the most of YourDictionary. By signing in, you agree to our Terms and Conditions adj. In West Faulkner v London Borough of Newham,3 the Court of Appeal examined a nearly identical clause to that in the JCT standard forms and concluded: Taken together the obligation upon the contractor is essentially to proceed continuously, industriously and efficiently with appropriate physical resources so as to progress the works steadily towards completion substantially in accordance with the contractual requirements to time, sequence and quality of the works. [Emphasis added]. Use our search box to check present tense, present participle tense, past tense and past participle tense of desired verb. Activity 1 : Personal Entrepreneurial Competencies MULTIPLE CHOICE: Choose the correct answer from the given option and write your answer on a one half crosswise sheet of paper. Improve your vocabulary with English Vocabulary in Use from Cambridge.Learn the words you need to communicate with confidence. Add industriously to one of your lists below, or create a new one. ), and in view of the circumstances of the Assyrian domination, it is probable that, so far as Palestinian economic conditions permitted, a legislation more progressive than the Pentateuch Paltistinas Erdgeruch in der Israel. This is so even though the delay has been caused by the contractors general lack of productivity and failure to proceed with priority areas in the first place. All rights reserved. Our thesaurus contains synonyms of diligently in 38 different contexts. !, Sta is a 16-year-old high school student who was recruited to work at the family restaurant Wagnaria by Popura. Without being very plentiful anywhere, it is generally distributed in suitable localities throughout its range - those localities being such as afford it a sufficient supply of food, consisting during the greater part of the year of insects, which it diligently seeks on the boles and larger limbs of old trees; but in autumn and winter it feeds on nuts, beech-mast, the stones of yew-berries and hard seeds. We have listed all the similar and related words for diligently alphabetically. In primitive cultures around the world, the wisest man or woman in the tribe was the shaman, the healer who could communicate with the spirit world. However, pinning the contractor down to rigid milestone dates with delay liquidated damages attached to them brings its own problems. and Remote jobs for Digital Working Nomads. Californias online employment resource. The consequences of getting it wrong can be high. The diligence obligation survives and instead attaches to the nearest possible approximation to proper contractual performance, namely, the contractual objective of minimising the ongoing breach. Stick with it, work diligently and you'll arrive at the end. (. A client called merecently to discuss an issue that is probably familiar to many clients. 'pa pdd chac-sb tc-bd bw hbr-20 hbss lpt-25' : 'hdn'">, Example from the Hansard archive. In copper-engraving Diirer was at the same time diligently training himself to develop the methods practised by Martin Schongauer and earlier masters into one suitable for his own self-expression. Your email address will not be published. He worked diligently at original manuscript authorities at Simancas, the Record Office and Hatfield House; but he used his materials carelessly, and evidently brought to his investigation of them a mind already made up as to their significance. There is a divine element to it whereby God will dispense wisdom to those who diligently seek it. I want to receive exclusive email updates from YourDictionary. Greek models were diligently studied by Virgil and Horace. This is a very interesting topic, given that it refers to a Saudi Arabian related dispute and that without exception all of the contracts let in Saudi Arabia barr none, fall into serious delay. Forum discussions with the word(s) 'diligently' in the title: Discussioni su 'diligently' nel forum English Only, Una o pi discussioni del forum combaciano perfettamente col termine che hai cercato, Journalists should diligently seek out subjects of news stories to give them the opportunity to respond to allegation of wrongdoing, by planning carefully and working diligently [repeating a preposition], looked out for the penitence as diligently, Study diligently and make progress everyday. He said due diligence is not determined subjectively by reference to the individual contractors achievements (or lack of them): it is a contractual requirement with which the contractor must comply; and it is to be assessed in the light of the other contractual obligations that the contractor has undertaken. Although Facebook works diligently to prevent violations to your privacy, for example through Facebook profile trackers, you should still take steps to protect yourself as well. So what could go wrong? Examples, Meaning, and Usage. The case of Vivergo Fuels v Redhall Engineering Solutions4 provides a useful insight into how a court is likely to evaluate whether there has been a failure to proceed regularly and diligently. He continued, however, to devote himself diligently to the pursuits of science, and published many remarkable memoirs. To understand what a gerund is, imagine your doorbell rings on Halloween. working ngha, nh ngha, working l g: 1. relating to work: 2. having work: 3. operating: . Numerous new fields were opened up, and have been diligently explored by many mathematicians. PastTenses is a database of English verbs. The shamans power came from the depth of their communication with this inner figure, which was The series stars Fred Savage and an ensemble cast including Maurice Godin, Arden Myrin, Yvette Freeman, and Steve Hytner . As Lord Hoffman stated in Mannai Investments Co Ltd v Eagle Star Assurance11: If the clause had said that the notice had to be on blue paper, it would have been no good serving a notice on pink paper.
Industrial Sociology Jobs In Zimbabwe,
What Does Nodding Your Head Mean In Different Cultures,
Top High School Baseball Prospects In Arizona,
Marine Corps Ocs Dates 2022,
Articles W